1. APPLICATION OF THESE TERMS AND CONDITIONS 

In this Agreement, the “Contractor” is Solar Set Pty Ltd ABN 88 653 447 486 trading as Solar Set, its successors and assigns or any person acting on behalf of and with the authority of Solar Set Pty Ltd.

The “Customer” is the person or entity requesting goods and services from the Contractor and named as the Customer on the Contractor’s quote and any other Customer paperwork.

“Goods” means all goods sold, leased, rented, consigned, bailed or otherwise made available to the Customer by the Contractor including but not limited to electrical equipment and associated components

“Site” means the place where the Contractor’s services will be carried out.

“Services” mean the Contractor’s performance of electrical work and associated services. 

2. QUOTES 

2.1 Contractor’s Quote  

The Contractor will provide the Customer a quote specifying the Goods and Services required to fulfill the Customer’s instructions and a cost estimate for such Goods and Services.  

2.2 Acceptance by the Customer  

Where the Contractor has given the Customer a quote: 

a) the Customer shall accept the quote by signing and returning a true copy of the quote

b) quotes are valid for thirty (30) days only unless an extension has been authorised by the Contractor

c) the Customer warrants that it has not relied on any representation by the Contractor other than as supplied in writing in the quote. 

2.3 Contractor May Revise Quote  

The Contractor may amend a quote, if not accepted within thirty (30) days from the date of the quote, to take into account any rise or fall in the cost of Goods and Services as quoted and the Contractor shall notify the Customer of such amendment as soon as practicable thereafter. The Contractor will not be obliged to commence the Services until such time as the Customer agrees to the amendment of the quote. 

2.4 Pricing 

If there is any error or omission in the Quote, Solar Set reserves the right to change the contract sum on the Quote. This clause applies even if the Quote has been accepted by the customer. Prices quoted are subject to final review by Solar Set.  

2.5 Force Majeure 

Solar Set shall not be liable for any failure or delay in the supply or delivery of the products or works where such failure or delay is wholly or partly due to any cause or circumstances whatsoever outside the  reasonable control of Solar Set, including, but not limited to war, strikes, lockouts, industrial disputes or unrest, government restrictions or intervention transport delays, fire, an act of God, breakdown of plant, shortage of supplies or labour, storm or tempest, theft, vandalism, riots, civil commotions or accidents of any kind.  

2.6 Products & Works 

If any products and works specified within this quotation are unavailable at the time of works being carried out, Solar Set in its absolute discretion may substitute a reasonable alternative.  

3. CANCELLATION  

The Customer shall reimburse the Contractor for any costs, losses or expenses incurred by the Contractor should the Customer cancel an accepted quote. The time for payment of such cancellation shall be seven (7) days from the date of the Contractor’s tax invoice. 

4. WORK IN PROGRESS  

The Customer shall provide exclusive Site access for the Contractor to complete any necessary work. Any interruptions due to no no limited Site access or work by other trades or the Customer causing down-time may be billed at the Contractor’s hourly rate. Rates are available from the Contractors representative.  

5. UNFORSEEN CIRCUMSTANCES/PRIOR WORK 

The Contractor shall not be liable for any problems with the Site due to another contractor’s prior work or latent conditions which are only revealed when installing the Goods. The Contractor will carry out any work required to remediate any such problem if it is considered necessary for satisfactory installation of the Goods. Any additional work necessary due to these  circumstances is a variation and subject to Clause 9.

6. SERVICES BELOW THE GROUND 

The Customer must clearly mark the exact location and identify all services above and below the ground that the Customer initiated at the Site, including but not limited to drains, pipes, sewers, mains and telephone and data cables, to enable the Contractor to prevent damage to all such services. Should the Customer fail to provide the Contractor with the location of services the Customer has initiated, then the Customer shall indemnify the Contractor from any claim for costs, expenses or losses. 

7. ‘DO AND CHARGE’ 

The hourly rate for ‘Do and Charge’ work may change should the Contractor experience latent conditions or obstacles requiring the hire of special equipment to complete the work. Should the ‘Do and Charge’ work prove to be more substantial than first envisaged, then the Contractor reserves the right to raise a quote for the work. Before any further work is performed by the Contractor the Customer must accept the quote in a manner as specified in clause 2.2.  

8. CONTRACTOR’S TRADING HOURS 

The Contractor’s normal trading hours are 7am to 5pm Monday to Friday. Work performed (at the Customer’s request) outside those hours or on a public holiday will be at the Contractor’s discretion and will be subject to after hours rates.

9.VARIATIONS 

9.1 All requests for variations by the Customer or the Customer’s Agent must be made direct to the Contractor’s office during normal business hours.

9.2 The Customer shall indemnify the Contractor from any additional cost incurred by the Contractor should the Customer increase the scope of the Works and/or Goods to be provided.

9.3 If a response to a variation requested by the Contractor has not been received from the Customer within two (2) business days, the Contractor will carry out the Works described as part of its Scope of Works. Such variations may result in additional charges to the original Quote/Contract. 

9.4 The Customer agrees to indemnify the Contractor from hold up and lost time and any costs and expenses due to variation work requested or agreed to by the Customer.  

9.5 The Customer agrees to make no claim against the Contractor for liquidated damages related to delays due to variations that were requested by the Customer.  

9.6 Payment terms for variations shall be seven (7) days from date of invoice. Variations within a period subject to a progress payment shall be payable at that time and no later. 

10. PAYMENT AND DEFAULT 

10.1 Time for Payment  

Unless otherwise agreed in writing the Contractor’s payment terms are strictly seven (7) days from the date of the Contractor’s tax invoice. 

10.2 Deposit  

The Contractor may require a deposit from the Customer and the Customer acknowledges the Contractor is under no obligation to undertake any work as requested by the Customer until the deposit is received by the Contractor in full and when all details pertaining to contract are finalised. In the event of default as to payment owing to the Contractor on the part of the Customer, the Contractor shall be entitled to forfeit the deposit and claim any profit or margin contemplated by or allowed for in the contract in addition to any remedy available to the Contractor at law or in equity.  

10.3 Payment Claims 

The Contractor shall make any payment claims in accordance with The  Building and Construction Industry Payments Act 2004. The Customer must respond appropriately and within the time specified in the Act. 

10.4 Payment Plan 

From time to time the Contractor may offer Customers a payment plan, spreading payment over a specified period with reoccurring payments. A formal Payment Plan Agreement would need to be entered into and such an agreement would include the Contractor’s Terms and Conditions of Trade. 

10.5 Progress Payments  

When agreed progress payments are not honoured by the Customer, the Contractor reserves the right to halt the Services until such time as the outstanding payment is forthcoming. In addition, clauses 10.6, 10.7 and 10.8 may apply. 

10.6 Administration Fee 

The Contractor reserves the right to charge a monthly fee of twenty-five dollars ($25) for any accounts not paid within the Contractor’s agreed payment terms. 

10.7 Interest  

The Contractor may charge interest at fifteen percent (15%) per annum calculated on a daily basis on amounts not paid within the Contractor’s payment terms. 

10.8 Damages 

The Customer must pay to the Contractor any costs, expenses or losses incurred by the Contractor as a result of the Customer’s failure to pay to the Contractor all sums outstanding as owed by the Customer to the Contractor including without limiting the generality of the forgoing any debt collection and legal costs incurred in enforcing payment on a solicitor and own client basis. 

11. RETENTION OF TITLE  

11.1 Title  

Notwithstanding the delivery of the Goods or their installation, title in any particular Goods shall remain with the Contractor regardless of whether the Goods are on-sold by the Customer until the Customer has paid and discharged any and all monies owing pursuant to any invoice issued by the Contractor for the Goods, including all applicable GST and other taxes, levies and duties. Where the Goods have been on-sold by the Customer, the Customer will be taken to hold the proceeds of sale of such Goods upon trust for the Contractor and to account to the Contractor for these proceeds. Any payment made by or on behalf of the Customer which is later avoided by the application of any Statutory Provisions shall be deemed not to discharge the Contractor’s title in the Goods nor the Customer’s indebtedness to the Contractor and, in such an event, the parties are to be restored to the rights which each respectively would have had if the payment had not been made. 

11.2 Bailment 

The Customer acknowledges that it is in possession of the Goods solely as Bailee until payment of all invoices for the Goods is made pursuant to clause 11.1 and until that time the Customer must not encumber or otherwise charge the Goods and the Customer shall be fully responsible for any loss or damage to the Goods whatsoever and howsoever caused following delivery of the Goods.‍

11.3 Repossession  

The Customer hereby irrevocably grants to the Contractor the right, at its sole discretion, to remove or repossess any Goods from the Customer and sell or dispose of them, and the Contractor shall not be liable to the Customer or any person claiming through the Customer and the Contractor shall be entitled to retain the proceeds of any Goods sold and apply same towards the Customer’s indebtedness to the Contractor. If the Customer commits an act of bankruptcy, enters into any form of administration or liquidation, makes any composition or arrangement with its creditors,  ceases to carry on business or breaches any fundamental clause of this  agreement, then the Contractor may, without prejudice to any other  remedies it may have, repossess any Goods delivered to the Customer on  any account which has not been paid in accordance with the Terms and  Conditions herein and commence proceedings to recover the balance of any  monies owing the Contractor by the Customer. 

12. PERSONAL PROPERTY SECURITIES ACT (PPSA) 

12.1 In this clause, the following words have the respective meanings  given to them in the PPSA: Financing Statement, Financing Change  Statement, Proceeds, Register, Security Agreement, Security Interest and  Verification Statement. In this clause “the Customer” is the grantor and  “the Contractor” is the secured party, as defined in the PPSA. 

12.2 The Customer acknowledges and agrees: 

a) that these Terms and Conditions constitute a Security Agreement that creates a Security Interest in all Goods (and Proceeds): 

(i) previously supplied by the Contractor to the Customer; 

(ii) to be supplied in the future by the Contractor to the Customer; 

b) that the Security Interest created by these Terms and Conditions is a continuing Security Interest in all Goods (supplied now or in the future by the Contractor to the Customer) and Proceeds, which will operate (despite any intervening payment of settlement of account) until the Contractor has signed a release; and 

c) to waive its rights under section 157 of the PPSA and the following subsections of section 115 of the PPSA, which will not apply to the Security Agreement created by these Terms and Conditions: 95, 118, 121(4), 130, 132(4), 135, 143. 

12.3 The Customer undertakes to: 

a) keep all Goods free of any charge, lien or Security Interest except as created under these Terms and Conditions and not otherwise deal with the Goods in a way that may prejudice any rights of the  Contractor under these Terms and Conditions or the PPSA; 

b) sign any further documents and provide any further information (which must be complete, accurate and up-to-date in all respects) that designer may require to: 

(i) register a Financing Statement or Financing Change Statement in relation to a Security  

Interest on the Register; 

(ii) register any other document required to be registered by the PPSA; or 

(iii) correct a defect in a statement referred to in clause 12.3(b) (i) or 12.3(b)

c) indemnify, and upon demand reimburse the Contractor for all fees (including actual legal fees on a solicitor/own Customer basis), costs, disbursements and expenses in: 

(i) registering and maintaining a Financing Statement or Financing Change Statement on the Register or releasing any Goods charged thereby; and 

(ii) enforcing or attempting to enforce the Security Interest created by these Terms and Conditions. 

d) not register, or allow to be registered, a Financing Statement or a Financing Change Statement in respect of the Goods, or Proceeds  in favour of a third party, without the prior written consent of the  Contractor; and 

e) immediately advise the Contractor of any material change in its business details (including, but not limited to, it’s trading name, address, fax number) or business practices. 

13. SCHEDULE OF WARRANTIES 

13.1 To the extent required by the Australian Consumer Law (“ACL”), the Contractor warrants that:  

a) the Works will be carried out in accordance with all relevant laws and legal requirements in an appropriate and skilful way, in accordance with the plans and specifications (where relevant) using Goods that are good and suitable for the purpose for which they are intended to be used and that, unless otherwise stated in the Contract, those Goods will be new; and 

b) each provisional sum item allowance, if calculated by the Contractor, has been calculated with reasonable skill and care, having regard to all the information reasonably available when the Contract is entered into (including information about the nature and location of the Site). 

13.2 The Contractor warrants that the Works are, and that Goods supplied are, free of defects at the time of completion and/or installation.  

13.3 If the Contractor be directed to reuse any materials or components from the Site or elsewhere, then the Contractor will not accept any responsibility for the aesthetic finishes, structural entity or any warranties whatsoever attached to those materials or components. The Customer shall indemnify the Contractor from any costs, losses or expenses associated with the rectification or resupply of such materials or components.  

13.4 Subject to the ACL, the Contractor does not have to fix any problem caused by misuse, abuse, wear and tear, damage caused by vermin, lizards and insects, or normal shrinkage or movement, minor colour variation in natural products, work done by others or any defects in Goods supplied by the Customer. 

14. LIABILITY 

14.1 Non-excludable Rights  

The parties acknowledge that, under the Australian Consumer Law, certain conditions and warranties may be implied in these Terms and Conditions and there are rights and remedies conferred on the Customer in relation to the provision of the Goods and Services which cannot be excluded, restricted or modified by the contract (“Non-excludable Rights”). 

14.2 Disclaimer of Liability  

The Contractor disclaims all conditions and warranties expressed or implied, and all rights and remedies conferred on the Customer, by statute, the common law, equity, trade, custom or usage or otherwise and all those conditions and warranties and all those rights and remedies are excluded other than any Non-excludable Rights. To the extent permitted by law, the liability of the Contractor for a breach of a Non-Excludable Right is limited, at the Contractor’s option, to the supplying of the Goods and Services again or payment of the cost of having the Goods and Services supplied again. 

14.3 Indirect Losses  

Notwithstanding any other provision of these Terms and Conditions, the Contractor is in no circumstances (whatever the cause) liable in contract, tort including without limitation, negligence or breach of statutory duty or  otherwise to compensate the Customer for: 

a) any increased costs or expenses; 

b) any loss of profit, revenue, business, contracts or anticipated savings; 

c) loss or expense resulting from a claim by a third party; or d) any special, indirect or consequential loss or damage of any nature whatsoever caused by the Contractor’s failure to  complete or delay in completing the Services within a reasonable  time. 

14.4 Force Majeure 

The Contractor will have no liability to the Customer in relation to any loss, damage or expense caused by the Contractor’s failure to complete the Services or to deliver the Goods as a result of fire, flood, tempest, earthquake, riot, civil disturbance, theft, crime, strike, lockout, breakdown, war, the inability of the Contractor’s normal suppliers to supply products or  any other matter beyond the Contractor’s control. 

15. PRIVACY 

15.1 The Customer authorises the Contractor to collect, retain, record, use  and disclose commercial and/or consumer information about the Customer, in accordance with the Privacy Act 1988 and the Privacy Principles outlined in the Privacy Amendment Act 2012, to persons and/or legal entities who are a solicitor or any other professional consultant engaged by the Contractor, a debt collector, credit reporting body and/or any other  individual or organisation which maintains credit references and/or default  listings. This information may be given before, during or after the provision of credit to the Customer. 

15.2 Subject to the Privacy Principles outlined in the Privacy Amendment Act 2012, the Customer further authorises the Contractor to collect, retain, record, use and disclose personal information for the marketing of Goods and Services provided by the Contractor. 

16. ARBITRATION AND MEDIATION 

Any dispute or difference between the Customer and the Contractor may be notified by a party to the other party and the parties shall firstly meet to negotiate, in good faith, resolution of the dispute and secondly, if negotiation fails to achieve a resolution of the dispute within five (5)  working days of the notification of the dispute, attend mediation, administered in accordance with procedures as set out by the Institute of Arbitrators and Mediators Australia, provided that this provision shall not  prevent the Contractor from instituting legal action at any time to recover  monies owing by the Customer to the Contractor. 

17. SECURITY AND CHARGE 

The Customer hereby charges all property, both equitable and legal, present or future of the Customer in respect of any monies that may be owing by the Customer under these Terms and Conditions or otherwise and hereby authorises the Contractor or its solicitors to execute any consent form as its attorney for the purpose of registering a caveat over any real property owned by the Customer at any time. 

18. GENERAL MATTERS 

18.1 Non-Waiver 

Failure by the Contractor to enforce or delay in enforcing any right or provision of these Terms and Conditions will not constitute a waiver of such right or provision unless acknowledged by in writing. 

18.2 Amendments to these Terms and Conditions 

The Contractor reserves the right to vary these Terms and Conditions at any time with notice in writing to the Customer. Any subsequent signed quote or work order will represent the Customer’s agreement to these Terms and Conditions as amended. 

18.3 Severability  

Any provision in these Terms and Conditions which is invalid or unenforceable in any jurisdiction must be read down for the purposes of that jurisdiction, if possible, so as to be valid and enforceable. If that provision cannot be read down then it is capable of being severed to the extent of the invalidity or unenforceability without affecting the remaining provisions of these Terms and Conditions or affecting the validity or enforceability of that provision in any other jurisdiction. 

18.4 Governing Law and Jurisdiction 

These Terms and Conditions are governed by the laws of the State of Queensland and the laws of the Commonwealth of Australia which are in force in Queensland. All disputes arising between the Customer and the Contractor will be submitted to a court of competent jurisdiction in Queensland selected by the Contractor and such court shall possess territorial jurisdiction to hear and determine such proceedings. 

19. SOLAR QUOTES & JOBS (if applicable) 

19.1 Start of Agreement 

This agreement starts when you accept our offer set out in the Quote, which you can do by:  

a) signing and posting or delivering the Quote to our address as set out in the Quote  

b) signing, scanning and emailing the Quote to our email address as set out in the QUOTE; or  

c) accepting the offer over the telephone, but calling our  telephone number as set out in the QUOTE (in which case  we will send you a full copy of this agreement by post, or  email, within one week after your acceptance).  

19.2 Purchase of Solar System  

However, your purchase of the System will not become final until all the following conditions have been satisfied:  

a) you have paid us the Deposit; and  

b) your electricity distributor has granted Grid Connection Approval 

19.3 End of Agreement 

This agreement ends when Solar Set have finished installing and commissioning the System, unless we or you end it earlier in accordance with its terms.  

19.4 Payment of Deposit  

You must pay us the Deposit at the same time as you accept the offer set out in the Quote. 

19.5 Payment of Balance  

You must pay the Balance upon completion of the installation and commissioning of the System to the Site.  

19.6 Refunds 

If you have paid us money under this agreement, but the agreement ends for any of the following reasons before we install the System at your Premises, then when the agreement ends we will promptly refund all the money you have paid: 

a) if we have not delivered and installed the System at the Premises within 4 weeks after the original Target Date, and you choose to end the agreement under clause 19.9; 

b) Grid Connection Approval is refused 

c) If any of the equipment quoted is unattainable and you do not agree to equipment of a similar quality to be substituted.  

d) If there is a change in system design from what was agreed upon at time of sale and is not acceptable to the consumer 

e) If the site performance estimate is provided after the cooling off period and the consumer does not consent to it upon receival  

f) Additional charges occurring on top of what was agreed upon at time of contract and is not acceptable to the consumer.  

19.7 Grid Connection Approvals  

We will apply for Grid Connection Approval on your behalf. In doing this, we will: 

a) Make the application as soon as possible 

b) Keep you updated on the progress of the application; 

c) Respond, within a reasonable timeframe, to any information or other requests from the distributor; and  

d) Promptly give you notice of the outcome of the application. 

19.8 Payment of Balance  

Provided you have paid the Balance, we must install the System at the Premises, in accordance with the Full System Design.  

19.9 Target Date 

We will use reasonable endeavours to deliver and install the System at the Premises on the Target Date.  

You agree, however, that  

a) The Target Date is only a target and not a strict deadline; and 

b) We will not be liable to you if we fail to deliver and install the System at the Premises by the Target Date.  

We will notify you if we do not think we can deliver and install the System at the Premises by the Target Date and give you a new Target Date.  

If we have not delivered and installed the System at the Premises within 4 weeks after the original Target Date, you can end this agreement and, if you do, we will give any refund required under clause 19.6 (a).  

19.9.1 Installation Requirements  

After installation of the System, we will give you any certificate or similar document regarding the electrical safety of the System which is required by law.  

We will take every reasonable precaution in installing the System at the Premises, however, we will not be liable in respect of: 

a) The structural integrity of the roof  

b) The roof’s ability to carry the weight of the System; 

c) Any effect installation of the System has on any roof manufacturer’s warranty; or  

d) Any damage to the roof or Premise which is not due to our negligence or breach of this agreement 

19.9.2 Accessing the Premises 

You grant us permission to enter and remain at the Premises to: 

a) Conduct one or more site inspections, if we think this is necessary; and  

b) Deliver and install the System,  

At any reasonable time, provided we give you notice of the proposed access time.  

You must:  

a) Ensure we have convenient and safe access to all parts of the Premises necessary to conduct any required site inspections or delivery and install of the System.  

b) Not hinder or obstruct the access; and  

c) Ensure the Premises, including its roof, supporting structures and electrical wiring, are sound and able to accommodate installation of the System.  

19.9.3 System Maintenance  

We must provide you with the Maintenance Documents It is your responsibility to maintain the System in accordance with these documents  

19.9.4 System Warranties  

Subject to clause 19.9.4, we guarantee:  

a) Our workmanship, and the workmanship of our contractors, in installing the System; and  

b) The operation and performance of the system,  

Will be free from fault or defect for a period of 5 years commencing the date the System is installed (Warranty Period), and we will repair any such default and defect notified to us within the Warranty Period, including by replacing all or part of the System where necessary, within a reasonable timeframe at no cost to you.  

The guarantee in the above clause will not apply where: 

a) The fault or defect is not notified to us within the Warranty Period; or  

b) The fault or defect is a result of:  

c) Something done by you or someone else and not us; or 

d) Something beyond human control that occurred after installation, e.g., an extreme weather event;  

e) The System being misused, abused, neglected or damaged after installation;  

f) The System being maintained other than in accordance with the Maintenance Documents; or  

g) The System being repaired, modified, reinstalled or repositioned by anyone other than a service technician approved by us in writing.  

The guarantee above is additional to any other guarantee or warranty you may have:  

a) From the manufacturer of the System; or  

b) Under any applicable law, including the Australian Consumer Law,  

Although these other guarantees or warranties may not cover labour costs, travel costs and delivery costs arising from a claim under these other guarantees and warranties. We will notify you if this is the case and tell you the costs payable. The costs will be payable in advance.  

During the Warranty Period, we will provide reasonable assistance to you in making guarantee or warranty claim against the manufacturer of the System, including by acting as your liaison with the manufacturer.